INVITATION TO BIDDERS THE PITTSBURGH WATER AND SEWER AUTHORITY ADVERTISEMENT SEPARATE and SEALED BIDS for the following solicitation, will be received by the Office of Procurement, Pittsburgh Water and Sewer Authority, 1200 Penn Ave., Second Floor, Pittsburgh, PA 15222, until 2:00 PM Prevailing Time May 11, 2016. INVITATIONS FOR BIDS (IFB) FOR 2016 Sewer Lining Contract PWSA PROJECT NO. 2016-424-228-0 All bids must be submitted in accordance with the solicitation that can be obtained by sending an e-mail to cjuratovic@pgh2o.com. There will be no charge for the solicitation, as it will be sent via e-mail. All questions relating to the solicitation itself shall be directed to Jim Tracey, Contract Specialist, via e-mail: jtracey@pgh2o.com, no later than May 4, 2016. Bids must be accompanied by a Bid Bond in the amount of Ten Percent (10%) of the bid for the project under construction. Said Bond shall be duly and legally executed with a Surety or Trust Company which has complied with City Ordinances/Resolutions relating thereto. A Performance Bond and Labor and Material Bond in the amount of 100% of the contract value for each awarded project will be required after award. The Contractor must assure that employees and applicants for employment are not discriminated against because of their race, color, religion, sexual preference, sex, or national origin. The bidders will be required to submit the package of certifications included with the contract documents relating to Equal Employment Opportunity. The Authority reserves the right to withhold the award of the Contract for a period of 60 days after the opening of the bids. The Authority reserves the right to reject any or all proposals, and to waive any informality or minor irregularity in any bid or bids. The Authority also retains the right to investigate the qualifications of bidders prior to any award and to award contracts only to contractors who, in the sole judgment of the Pittsburgh Water and Sewer Authority, are qualified and equipped to properly execute the specified work. DAVID DONAHOE INTERIM EXECUTIVE DIRECTOR THE PITTSBURGH WATER AND SEWER AUTHORITY
INVITATION TO BIDDERS THE PITT...
↧
↧
SUHY, ROBERT G., DECEASED, OF ...
SUHY, Robert G., deceased, of Bethel Park, PA. No. 2253 of 2016. Sonia J. Suhy, Extrx., c/o Joan Shinavski, Esq., McKay & Associates, P.C., Unicorn Professional Plaza, 3755 Library Rd., Suite 301, Pittsburgh, PA 15234
↧
BERARDI, VAL, A/K/A VALENTINO ...
BERARDI, Val, a/k/a Valentino Berardi, deceased, of Glenshaw, PA. No. 215 of 2016. Lisa Berardi Marflak, Extrx., c/o Christopher M. Abernethy, Esq., The Law Office of Christopher M. Abernethy, LLC, 4499 Mt. Royal Blvd., Allison Park, PA 15101.
↧
JENNIFER S. DICKQUIST, ESQ., N...
JENNIFER S. Dickquist, Esq., Notaro & Associates, P.C., 310 Grant St., Suite 1125, Pittsburgh, PA 15219. IN The Court of Common Pleas of Allegheny County, Pennsylvania: No. GD-16-4366, In re petition of Jennifer Yvonne Stathopoulos for change of name to Jennifer Yvonne Sentner. To all persons interested: Notice is hereby given that an order of said Court authorized the filing of said petition and fixed the 10th day of May, 2016, at 9:45 a.m., as the time and the Motions Room, City-County Building, Pittsburgh, PA, as the place for a hearing, when and where all persons may show cause, if any they have, why said name should not be changed as prayed for.
↧
NOTICE OF HEARING ON PETITION ...
NOTICE OF HEARING ON PETITION FOR TERMINATION OF PARENTAL RIGHTS IN RE: Ava June Blackwell a/k/a Ava Blackwell, a minor. NO. AP-0071-2016 in the Orphans' Court Division of the Court of Common Pleas of Allegheny County, Pennsylvania. TO: Sandra Jeanne Sienko a/k/a Sandra Jeanne Lipchak a/k/a Sandra Lipchak, Kevin Early Blackwell a/k/a Kevin Blackwell and Stephen Matthew Lipchak, parents of Ava June Blackwell a/k/a Ava Blackwell, a minor, born on December 16, 2014 in Allegheny County, Pennsylvania. A petition has been filed asking the court to put an end to all rights you have to your child, Ava June Blackwell a/k/a Ava Blackwell. The court has set a hearing to consider ending your rights to your child. A hearing will be held at the Family Court Building, 550 Fifth Avenue, Pittsburgh, Pennsylvania, on May 25, 2016 at 9:00 a.m. (Prevailing Eastern Time), before the Honorable Jennifer McCrady. You are warned that even if you fail to appear at the scheduled hearing, the hearing will go on without you and your rights to your child may be ended by the court without your being present. You have a right to be represented at the hearing by a lawyer. You should take this paper to your lawyer at once. If you do not have a lawyer or cannot afford one, go to or telephone the office set forth below to find out where you can get legal help. LAWYER REFERRAL SERVICE, THE ALLEGHENY COUNTY BAR ASSOCIATION, 1100 Koppers Building, 436 Seventh Avenue, Pittsburgh, Pennsylvania 15219, Telephone: 412-261-5555. ANDREW F. SZEFI, County Solicitor, LAURA J. WHITEMAN, Assistant County Solicitor, CONTACT: AMY BLACK, Esq., Adoption Legal Services Project, 225 Fifth Avenue, 9th Floor, Pittsburgh, PA 15222, (412) 288-3289, ATTORNEYS FOR PETITIONER.
↧
↧
THE NORTH ALLEGHENY SCHOOL DIS...
THE North Allegheny School District is receiving bids on the following Contracts; Planned Maintenance of Boilers and Burners at Various Bldgs.-Mechanical Planned Maintenance of Johnson Controls EMCS at Various Bldgs. - Electrical Planned Maintenance of Siemens Controls EMCS at Various Bldgs. - Electrical Planned Maintenance of Elevators and Dumb Waiters at Various Bldgs. - Mechanical Renovation of the Press Box at Newman Stadium - Rebid - General North Allegheny School District, the Owner, will receive separate sealed Bids for the construction Contracts on the above Project until the time and date and at the place scheduled below. The Bids will be publicly opened and read aloud in the Conference Room of the Facilities/Transportation Offices. The clock in the Conference Room will determine prevailing time for receipt of bids. The District invites interested parties to attend. BID DUE DATE: May 11, 2016 PROJECT & BID OPENING TIME: Planned Maintenance of Boilers & Burners, 1:00 P.M., Prevailing Time Planned Maintenance of Johnson Controls EMCS, 1:15 P.M. Prevailing Time Planned Maintenance of Siemens EMCS , 1:30 P.M., Prevailing Time Planned Maintenance of Elev. & Dumbwaiters, 1:45 P.M., Prevailing Time Renovate Press Box at Newman Stadium, 2:00 P.M., Prevailing Time PLACE OF RECEIPT: North Allegheny School District Transportation/Assets Department, Attn.: Mrs. Jaimie Nichols, Purchasing Manager PLACE OF OPENING: Facilities/Transportation Offices Conference Room, 400 Hillvue Lane, Pittsburgh, PA 15237 Bidders may obtain one complete set of the Bidding Documents for this Project by contacting the North Allegheny Facilities Department, North Allegheny School District, 400 Hillvue Lane, Pittsburgh, PA 15237, (412) 369-5432. A non-refundable deposit of $25.00 per set is required for all projects and must be in the form of a corporate, or business check made payable to "North Allegheny School District" and brought to the Facilities Department at North Allegheny School District Facilities/Transportation Office. Bidders who previously signed out the bidding documents for the renovation of the Press Box will not be required to purchase another set of plans and specs. If the bidding documents are to be mailed the deposit amount will be $50.00 for all projects. A Bid Security in the amount of 10 percent must accompany each Bid in accordance to the Instructions to Bidders. The Owner reserves the right to reject any or all Bids and to waive any informalities or irregularities in any Bid received. Bids will be received from Bidders who have registered with North Allegheny School District Facilities Department and purchased a complete set of Bidding Documents as a Prime Bidder. Registration is required to ensure Bidders receive Addenda and Bid related correspondence. The Bidding Documents will not be accepted for return at the receipt of Bids. For more information on these projects please contact the following Consultants; Project & Contact PM of Boilers & Burners , Mr. Shawn Bornes, NASD Facilities, Ph. 412-369-5432 PM of Johnson Controls EMCS , Mr. Shawn Bornes, NASD Facilities, Ph. 412-369-5432 PM of Siemens EMCS, Mr. Shawn Bornes, NASD Facilities, Ph. 412-369-5432 PM of Elevators & Dumbwaiters , Mr. Shawn Bornes, NASD Facilities, Ph. 412-369-5432 Renovate the Press Box, Mr. Bruce Pollock, RSSC Arch, Ph. 724-933-9100
↧
NOTICE OF ACTION IN MORTGAGE F...
NOTICE OF ACTION IN MORTGAGE FORECLOSURE IN THE COURT OF COMMON PLEAS OF ALLEGHENY COUNTY, PENNSYLVANIA CIVIL ACTION - LAW WILMINGTON SAVINGS FUND SOCIETY, FSB DBA CHRISTIANA TRUST AS TRUSTEE FOR HLSS MORTGAGE MASTER TRUST FOR THE BENEFIT OF THE HOLDERS OF THE SERIES 2014-1 CERTIFICATES ISSUED BY HLSS MORTGAGE MASTER TRUST, Plaintiff, vs. EDNA R. NELSON, in her capacity as Heir of MARJORIE NELSON, Deceased. UNKNOWN HEIRS, SUCCESSORS, ASSIGNS, AND ALL PERSONS, FIRMS, OR ASSOCIATIONS CLAIMING RIGHT, TITLE OR INTEREST FROM OR UNDER MARJORIE NELSON, DECEASED, Defendants. COURT OF COMMON PLEAS CIVIL DIVISION ALLEGHENY COUNTY No. GD-16-003101 NOTICE To UNKNOWN HEIRS, SUCCESSORS, ASSIGNS, AND ALL PERSONS, FIRMS, OR ASSOCIATIONS CLAIMING RIGHT, TITLE OR INTEREST FROM OR UNDER MARJORIE NELSON, DECEASED. You are hereby notified that on March 1, 2016, Plaintiff, WILMINGTON SAVINGS FUND SOCIETY, FSB DBA CHRISTIANA TRUST AS TRUSTEE FOR HLSS MORTGAGE MASTER TRUST FOR THE BENEFIT OF THE HOLDERS OF THE SERIES 2014-1 CERTIFICATES ISSUED BY HLSS MORTGAGE MASTER TRUST, filed a Mortgage Foreclosure Complaint endorsed with a Notice to Defend, against you in the Court of Common Pleas of ALLEGHENY County Pennsylvania, docketed to No. GD-16-003101. Wherein Plaintiff seeks to foreclose on the mortgage secured on your property located at 1622 WESTFIELD STREET, PITTSBURGH, PA 15216-3729 whereupon your property would be sold by the Sheriff of ALLEGHENY County. You are hereby notified to plead to the above referenced Complaint on or before 20 days from the date of this publication or a Judgment will be entered against you. NOTICE If you wish to defend, you must enter a written appearance personally or by attorney and file your defenses or objections in writing with the court. You are warned that if you fail to do so the case may proceed without you and a judgment may be entered against you without further notice for the relief requested by the plaintiff. You may lose money or property or other rights important to you. YOU SHOULD TAKE THIS NOTICE TO YOUR LAWYER AT ONCE. IF YOU DO NOT HAVE A LAWYER, GO TO OR TELEPHONE THE OFFICE SET FORTH BELOW. THIS OFFICE CAN PROVIDE YOU WITH INFORMATION ABOUT HIRING A LAWYER. IF YOU CANNOT AFFORD TO HIRE A LAWYER, THIS OFFICE MAY BE ABLE TO PROVIDE YOU WITH INFORMATION ABOUT AGENCIES THAT MAY OFFER LEGAL SERVICES TO ELIGIBLE PERSONS AT A REDUCED FEE OR NO FEE. Lawyer Referral Service Lawyer Referral Service, Allegheny County Bar Association, 400 Koppers Building, 436 7th Avenue, 3rd Floor, Pittsburgh, PA 15219, Telephone (412) 261-5555.
↧
BETHEL PARK SCHOOL DISTRICT S...
BETHEL PARK SCHOOL DISTRICT SUMMARY NOTICE UNDER LOCAL GOVERNMENT UNIT DEBT ACT Notice is hereby given that the Board of School Directors of the Bethel Park School District will, at a meeting to be held on Tuesday, April 26, 2016 at 8:00 PM in the Board Meeting Room at the Administrative Offices of the Bethel Park School District, 301 Church Road, Bethel Park, PA (or on such other date, not later than 30 days from the date of publication of this notice, and at such time and place, as the Board may lawfully determine), along with such other general business matters as may come before the Board, consider, and may then adopt, a resolution authorizing non-electoral debt in the presently estimated amount of $90,990,000, and summarized as follows: Article 1 defines certain terms, including the Bonds and the Project, which consists generally of (a) advance refunding all, or portions of, the School District's General Obligation Bonds, Series of 2009, in order to achieve debt service savings, (b) funding certain capital improvements to District facilities and (c) paying the costs of issuance of the Bonds. Articles 2 and 3 authorize the incurrence of non-electoral debt by the issuance of General Obligation Bonds and establish a sinking fund. Article 4 provides the form, maturity, amounts, interest rates and the terms and provisions for the payment of the Bonds. Articles 5, 6, 7 and 8 address the Sinking Fund Depository, events of default, and amendment and discharge of the security documents. Article 9 contains federal income tax covenants; Article 10, securities law covenants. Article 11 provides for the sale of the Bonds, establishes certain funds and sets forth certain directions for settlement, while Article 12 authorizes other related and necessary actions. The full text of the Resolution as proposed may be examined by any citizen between the hours of 9:00 AM to 4:00 PM on regular school business days at the office of the Secretary, Bethel Park School District, 301 Church Road, Bethel Park, PA 15102. BETHEL PARK SCHOOL DISTRICT, Matthew W. Howard, Secretary, 412-833-5000
↧
DEBTOR: GRECO ACQUISITIONS, I...
DEBTOR: GRECO ACQUISITIONS, INC., D/B/A HR EVANS STEEL COMPANY 193 James Street, East Palestine OH 44413 NOTIFICATION OF PUBLIC SALE AND DISPOSITION OF COLLATERAL ASSETS, AND OPPORTUNITY TO SUBMIT COMPETITIVE BID TAKE NOTICE: Greco Acquisitions, Inc. d/b/a HR Evans Steel Company ("Company") is indebted to JPMorgan Chase Bank, N.A. ("Secured Party"), 50 S. Main St., Floor 3, Akron, OH 44308, under a Credit Agreement, Pledge and Security Agreement and Forbearance Agreement ("Loan Documents"). To secure payment of Company's obligations, Secured Party holds a lien encumbering substantially all Company's personal property assets. Company is in breach of the Loan Documents. Pursuant to the Loan Documents and the Uniform Commercial Code enacted in the State of Ohio (the "UCC"), and based on relief obtained in Company's bankruptcy case in the US Bankruptcy Court, ND OH, Case No. 16-40573, Secured Party shall foreclose its security interests encumbering the Sale Assets (defined below) that are subject to Secured Party's liens, and thereby sell Company's right, title and interest in the Sale Assets at a public sale, as set forth herein, in accordance with the UCC and applicable law. TAKE FURTHER NOTICE: Pursuant to Article 9 of the UCC, Secured Party will sell and convey Company's right, title and interest in the Sale Assets at a public secured party sale to be held on May 2, 2016, at the offices of Benesch Friedlander Coplan & Aronoff LLP, 200 Public Square, Suite 2300, Cleveland, Ohio 44114, commencing at 10:00 am (prevailing Eastern time) (the "UCC Sale Date"). At the above UCC Sale Date, Secured Party will sell the Sale Assets to (i) DNV Investments, LLC or its designee (the "Proposed Buyer") pursuant to a Secured Party Asset Purchase Agreement dated March 17, 2016 between Proposed Buyer and Secured Party, as amended by a First Amendment (the "SP-APA") or (ii) to the highest qualified bidder that submits a higher and better qualified offer and Purchase Price (as defined in the SP-APA) in public at the time and location of the UCC Sale Date, as determined by Secured Party in its sole discretion ("Qualified Bid"), to purchase the Sale Assets, including on substantially the same terms as the SP-APA. Acceptance of any such Qualified Bid shall be determined by Secured Party. OPPORTUNITY TO BID: Any person or third party desiring to submit a Qualified Bid to purchase the Sale Assets at the time and location of the UCC Sale Date must: (1) Appear at the time and location of the UCC Sale Date and submit its highest and best bid to purchase the Sale Assets, or (2) On or before 10:00 am (Eastern time) on April 30, 2016, submit to counsel for Secured Party, William E. Schonberg, Benesch Friedlander Coplan & Aronoff LLP, at the above address or email to: wschonberg@beneschlaw.com (a) a written request to execute a Non-Disclosure & Confidentiality Agreement and, upon execution of which, such person will be provided a copy of the SP-APA, (b) a copy of the SP-APA modified to reflect an increased Purchase Price of not less than $25,000 cash as contained in the SP-APA (the "Minimum Upset Bid") and any improved related terms of such person's higher and better bid to purchase the Sale Assets under the SP-APA (as so modified) and (c) financial information evidencing such person's ability to close a transaction on the terms and conditions set forth in the submitted SP-APA as so modified. Such person must appear at the location and time of the UCC Sale Date. Furthermore, at such location and time such person may also submit a bid, and seek to have it determined to be a Qualified Bid, to purchase the Sale Assets. Any offer or bid that contains any terms or conditions less favorable than the terms of the SP-APA will not be a Qualified Bid, as shall be determined by Secured Party. At the time and location of the UCC Sale Date, Secured Party will consider successive bids by any party, upon bidding rules to be distributed by Secured Party at the UCC Sale Date. Secured Party may continue or cancel the UCC Sale of the Sale Assets as may be announced at the time and location of the UCC Sale Date. SALE ASSETS TO BE SOLD: Personal property assets consisting of Company's right, title and interest in inventory, including raw materials, work-in?process, finished goods, supplies and packaging; machinery and equipment; computer hardware and computer software; proprietary rights, including the name "HR Evans Steel Company"; customer lists, books and files, accounting and business books and records; and Company's rights under agreements between Company and any third parties which are identified. The Sale Assets do not include any real property, any Accounts (as defined in the UCC), any proceeds of insurance covering the Sale Assets and Company's corporate, minute or stock books and records. Company is entitled to an accounting of the unpaid indebtedness secured by the Sale Assets and of the proceeds of the Sale Assets that Secured Party intends to sell hereby. The Company may request an accounting, for a charge of $50.00, by contacting Secured Party.
↧
↧
DENK, THOMAS E. A/K/A THOMAS E...
DENK, Thomas E. a/k/a Thomas Edward Denk, deceased, of Brentwood Boro, PA. No. 1080 of 2016. Donna Kovach, Extrx., 508 East Garden Rd., Pittsburgh, PA 15227 or to Jeffrey J. Lochner, Esq., GBU Bldg., 4232 Brownsville Rd., Ste. 315, Pittsburgh, PA 15227.
↧
MITCHELL, ERIN, DECEASED, OF P...
MITCHELL, Erin, deceased, of Pittsburgh, PA. No. 7083 of 2015. Gina Mitchell & Laura Mitchell Dendy, Co-Extrxs., c/o Marsha C. Grayson, Esq., 401 Wood St., Ste. 850, Pittsburgh, PA 15222
↧
ANDERSON, BRIAN DOUGLAS, PITTS...
Anderson, Brian Douglas, Pittsburgh; Ehrman, Leah Claire, Sarver Csizmadia, Michelle Lee; Csizmadia, Charise Renee, Coraopolis Dixon, Lucy Anna; Gomez Cruz, Juventino, Pittsburgh Hollier, Dayna Lynn; Oyewole, Olawale, New Kensington Lucas, Stacy Lynne; Neill Sr., Christopher William, Pittsburgh Petrie, Ashley Lauren; Almara, Ronald Allen, Pittsburgh
↧
RANDY KOFFLER FROM JACLYN KOFF...
Randy Koffler from Jaclyn Koffler Perry A Napolitano from Susan C Napolitano Andrew J. Barilla from Raquel Ann Barilla Robert W. Ellison Jr. from Lillian Cheryl Ellison Kris A. Moser from Judith E. Moser Fadoua Loudiy from Andrew R. Smith
↧
↧
IN THE COURT OF COMMON PLEAS O...
IN The Court of Common Pleas of Allegheny County, Pennsylvania: No. GD-163046, In re petition of Jhoner Wessli Garcia Bejar for change of name to Jhoner Wessli Garcia. To all persons interested: Notice is hereby given that an order of said Court authorized the filing of said petition and fixed the 6th day of May, 2016, at 9:45 a.m., as the time and the Motions Room, City-County Building, Pittsburgh, PA, as the place for a hearing, when and where all persons may show cause, if any they have, why said name should not be changed as prayed for.
↧
PUBLIC NOTICE CITY OF CLAIRTON...
PUBLIC NOTICE City of Clairton Redevelopment Authority Public notice is hereby given that the Redevelopment Authority of the City of Clairton will meet on Thursday, April 28th, 2016 at 6:00 p.m., prevailing time in Clairton City Hall, 551 Ravensburg Blvd, Clairton, Pa. Howard J. Bednar City Manager
↧
DLUGOS, SYLVIA M., DECEASED, O...
DLUGOS, Sylvia M., deceased, of Carnegie, PA. No. 1367 of 2016. Carol Ann Dlugos, Extrx., 241 Marshall Ave., Carnegie, PA 15106, or to Richard J. Amrhein, Esq., Peacock Keller & Ecker, LLP, 70 East Beau St., Washington, PA 15301.
↧
PELCZARSKI, MARIE, DECEASED, O...
PELCZARSKI, Marie, deceased, of Reserve Twp., PA. No. 2016 of 2016. Edward L. Liker, Admr., c/o Rebecca A. Olds, Esq., Olds Russ & Associates, LLC, 1007 Mount Royal Blvd., Pittsburgh, PA 15223.
↧
↧
KELLER, ALICE, DECEASED, OF RO...
KELLER, Alice, deceased, of Ross Twp., PA. No. 1985 of 2016. Kristy Bohr, Extrx., c/o Rebecca A. Olds, Esq., Olds Russ & Associates, LLC, 1007 Mount Royal Blvd., Pittsburgh, PA 15223.
↧
MCKEE, VIRGINIA LOUISE, A/K/A ...
McKEE, Virginia Louise, a/k/a Virginia L., deceased, of Pittsburgh, PA. No. 1564 of 2016. Louise Ann (Luanne) Welsch, Extrx., 42 Redds Mill Rd., Charleroi, PA 15022, or to Lisa Sciullo Goodyear, Esq., Sciullo & Goodyear, Attys., 3809 Willow Ave., Pittsburgh, PA 15234.
↧
NOTICE OF ALLEGHENY COUNTY NOT...
NOTICE OF ALLEGHENY COUNTY Notice is hereby given that Allegheny County's Accountability, Conduct and Ethics Commission will meet on Monday, April 25th, 2016, at 4:00 PM. Meeting to be held in the Human Resources Conference Room, 542 Forbes Avenue, Room 102, Pittsburgh, PA 15219.
↧
More Pages to Explore .....
